Loading...
Resolution 2025-080Resolution No. 2025-80 RESOLUTION OF THE UNITED CITY OF YORKVILLE, KENDALL COUNTY, ILLINOIS APPROVING AN ENGINEERING AGREEMENT WITH ENGINEERING ENTERPRISES, INC. WHEREAS, the United City of Yorkville, Kendall County, Illinois (the "City') is a non - home rule municipality duly organized and validly existing in accordance with the Constitution of the State of Illinois and the laws of this State; and WHEREAS, the City's Public Works Department plans to construct a 1.5-million-gallon standpipe at 8621 IL Route 126 for the future South Receiving Station, including site grading and connection water main (the "Project"); and WHEREAS, completion of the Project will require engineering services conducted by an outside engineering firm; and WHEREAS, Engineering Enterprises, Inc., of Sugar Grove, Illinois ("EEI"), has prepared an agreement between EEI and the City for engineering services related to the Project (the "Agreement"), said Agreement being attached hereto as Exhibit A; and WHEREAS, EEI has provided engineering services for various projects completed by the City, and the City administration has found that EEI is a qualified and experienced engineering firm; and WHEREAS, the City administration recommends approval of the Agreement. NOW, THEREFORE, BE IT RESOLVED by the Mayor and City Council (the "Corporate Authorities") of the United City of Yorkville, Kendall County, Illinois, as follows: Section 1. The foregoing recitals are hereby incorporated in this Resolution as the findings of the Corporate Authorities. Section 2. The Mayor and City Clerk are hereby authorized to execute an Agreement Resolution No. 2025-80 Page 1 for Professional Services — South Receiving Station Standpipe (Construction), attached hereto as Exhibit A. Section 3. This Resolution shall be in full force and effect from and after its passage and approval according to law. Passed by the City Council of the United City of Yorkville, Kendall County, Illinois this 24" day of rune, A.D, 2025. w ITY CLERK KEN KOCH AYE DAN TRANSIER ABSENT ARDEN .IOE PLOCHER AYE CRAIG SOLING AYE CHRIS FUNKHOUSER AYE MATT MAREK AYE RUSTY CORNEILS AYE RUSTY HYETT AYE APPROVED by me, as Mayor of the United City of Yorkville, Kendall County, Illinois this oqc-{ day of A.D. 2025. Attest: 4CiClerk Resolution No. 2025-80 Page 2 SOUTH RECEIVING STATION UNITED CITY OF YORKVILLE STANDPIPE (CONSTRUCTION) Agreement for Professional Services South Receiving Station Standpipe (Construction) United City of Yorkville THIS AGREEMENT, by and between the United City of Yorkville, hereinafter referred to as the "City" or "OWNER" and Engineering Enterprises, Inc. hereinafter referred to as the "Contractor" or "ENGINEER" agrees as follows: A. Services: The ENGINEER shall furnish the necessary personnel, materials, equipment and expertise to provide construction administration, coordination, layout, and inspection and to complete all necessary engineering services to the City as indicated on the included Attachment B. Services to be provided include all professional engineering services for the construction of a new elevated water storage tank. All Engineering will be in accordance with all City, Standards for Sewer and Water Main Construction in Illinois and Illinois Department of Transportation requirements. B. Term: Services will be provided beginning on the date of execution of this agreement and continuing, until terminated by either party upon 7 days written notice to the non - terminating party or upon completion of the Services. Upon termination the ENGINEER shall be compensated for all work performed for the City prior to termination. C. Compensation and maximum amounts due to ENGINEER: ENGINEER shall receive as compensation for all work and services to be performed herein an amount based on the Estimate of Level of Effort and Associated Cost included in Attachment C and associated Scope of Work included as Attachment B. Construction Engineering will be paid for on an hourly or actual basis in a not to exceed amount of $394,744. The hourly rates for this project are shown in the attached 2025 Standard Schedule of Charges. All payments will be made accordingly to the Illinois State Prompt Payment Act and not less than once every thirty days. D. Changes in Rates of Compensation: In the event that this contract is designated in Section B hereof as an Ongoing Contract, ENGINEER, on or before February 1st of any given year, shall provide written notice of any change in the rates specified in Section C hereof (or on any attachments hereto) and said changes shall only be effective on and after May 1 st of that same year. PAGE 1 SOUTH RECEIVING STATION UNITED CITY OF YORKVILLE STANDPIPE (CONSTRUCTION) E. Ownership of Records and Documents: ENGINEER agrees that all books and records and other recorded information developed specifically in connection with this agreement shall remain the property of the City. ENGINEER agrees to keep such information confidential and not to disclose or disseminate the information to third parties without the consent of the City. This confidentiality shall not apply to material or information, which would otherwise be subject to public disclosure through the freedom of information act or if already previously disclosed by a third party. Upon termination of this agreement, ENGINEER agrees to return all such materials to the City. The City agrees not to modify any original documents produced by ENGINEER without ENGINEER'S consent. Modifications of any signed duplicate original document not authorized by ENGINEER will be at OWNER's sole risk and without legal liability to the ENGINEER. Use of any incomplete, unsigned document will, likewise, be at the OWNER's sole risk and without legal liability to the ENGINEER. F. Governing Law: This contract shall be governed and construed in accordance with the laws of the State of Illinois. Venue shall be in Kendall County, Illinois. G. Independent Contractor: ENGINEER shall have sole control over the manner and means of providing the work and services performed under this agreement. The City's relationship to the ENGINEER under this agreement shall be that of an independent contractor. ENGINEER will not be considered an employee to the City for any purpose. H. Certifications: Employment Status: The ENGINEER certifies that if any of its personnel are an employee of the State of Illinois, they have permission from their employer to perform the service. Anti -Bribery: The ENGINEER certifies it is not barred under 30 Illinois Compiled Statutes 500150-5(a) - (d) from contracting as a result of a conviction for or admission of bribery or attempted bribery of an officer or employee of the State of Illinois or any other state. Loan Default: If the ENGINEER is an individual, the ENGINEER certifies that he/she is not in default for a period of six months or more in an amount of $600 or more on the repayment of any educational loan guaranteed by the Illinois State Scholarship Commission made by an Illinois institution of higher education or any other loan made from public funds for the purpose of financing higher education (5 ILCS 385/3). Felony Certification: The ENGINEER certifies that it is not barred pursuant to 30 Illinois Compiled Statutes 500150-10 from conducting business with the State of Illinois or any agency as a result of being convicted of a felony. PAGE 2 SOUTH RECEIVING STATION UNITED CITY OF YORKVILLE STANDPIPE (CONSTRUCTION) Barred from Contracting: The ENGINEER certifies that it has not been barred from contracting as a result of a conviction for bid -rigging or bid rotating under 720 Illinois Compiled Statutes 5133E or similar law of another state. Drug Free Workplace: The ENGINEER certifies that it is in compliance with the Drug Free Workplace Act (30 Illinois Compiled Statutes 580) as of the effective date of this contract. The Drug Free Workplace Act requires, in part, that ENGINEERS, with 25 or more employees certify and agree to take steps to ensure a drug free workplace by informing employees of the dangers of drug abuse, of the availability of any treatment or assistance program, of prohibited activities and of sanctions that will be imposed for violations; and that individuals with contracts certify that they will not engage in the manufacture, distribution, dispensation, possession, or use of a controlled substance in the performance of the contract. Non -Discrimination, Certification, and Equal Employment Opportunity: The ENGINEER agrees to comply with applicable provisions of the Illinois Human Rights Act (775 Illinois Compiled Statutes 5), the U.S. Civil Rights Act, the Americans with Disabilities Act, Section 504 of the U.S. Rehabilitation Act and the rules applicable to each. The equal opportunity clause of Section 750.10 of the Illinois Department of Human Rights Rules is specifically incorporated herein. The ENGINEER shall comply with Executive Order 11246, entitled Equal Employment Opportunity, as amended by Executive Order 11375, and as supplemented by U.S. Department of Labor regulations (41 C.F.R. Chapter 60). The ENGINEER agrees to incorporate this clause into all subcontracts under this Contract. International Boycott: The ENGINEER certifies that neither it nor any substantially owned affiliated company is participating or shall participate in an international boycott in violation of the provisions of the U.S. Export Administration Act of 1979 or the regulations of the U.S. Department of Commerce promulgated under that Act (30 ILCS 582). Record Retention and Audits: If 30 Illinois Compiled Statutes 500120-65 requires the ENGINEER (and any subcontractors) to maintain, for a period of 3 years after the later of the date of completion of this Contract or the date of final payment under the Contract, all books and records relating to the performance of the Contract and necessary to support amounts charged to the City under the Contract. The Contract and all books and records related to the Contract shall be available for review and audit by the City and the Illinois Auditor General. If this Contract is funded from contract/grant funds provided by the U.S. Government, the Contract, books, and records shall be available for review and audit by the Comptroller General of the U.S. and/or the Inspector General of the federal sponsoring agency. The ENGINEER agrees to cooperate fully with any audit and to provide full access to all relevant materials. PAGE 3 SOUTH RECEIVING STATION UNITED CITY OF YORKVILLE STANDPIPE (CONSTRUCTION) United States Resident Certification: (This certification must be included in all contracts involving personal services by non-resident aliens and foreign entities in accordance with requirements imposed by the Internal Revenue Services for withholding and reporting federal income taxes.) The ENGINEER certifies that he/she is a: x United States Citizen Resident Alien Non -Resident Alien The Internal Revenue Service requires that taxes be withheld on payments made to non resident aliens for the performance of personal services at the rate of 30%. Tax Payer Certification : Under penalties of perjury, the ENGINEER certifies that its Federal Tax Payer Identification Number or Social Security Number is (provided separately) and is doing business as a (check one): Individual Real Estate Agent Sole Proprietorship Government Entity Partnership Tax Exempt Organization (IRC 501(a) only) x Corporation Not for Profit Corporation Trust or Estate Medical and Health Care Services Provider Corp. I. Indemnification: ENGINEER shall indemnify and hold harmless the City and City's agents, servants, and employees against all loss, damage, and expense which it may sustain or for which it will become liable on account of injury to or death of persons, or on account of damage to or destruction of property resulting from the performance of work under this agreement by ENGINEER or its Subcontractors, or due to or arising in any manner from the wrongful act or negligence of ENGINEER or its Subcontractors of any employee of any of them. In the event that the either party shall bring any suit, cause of action or counterclaim against the other party, the non -prevailing party shall pay to the prevailing party the cost and expenses incurred to answer and/or defend such action, including reasonable attorney fees and court costs. In no event shall the either party indemnify any other party for the consequences of that party's negligence, including failure to follow the ENGINEER's recommendations. J. Insurance: The ENGINEER agrees that it has either attached a copy of all required insurance certificates or that said insurance is not required due to the nature and extent of the types of services rendered hereunder. (Not applicable as having been previously supplied) K. Additional Terms or Modification: The terms of this agreement shall be further modified as provided on the attached Exhibits. Except for those terms included on the Exhibits, no additional terms are included as a part of this agreement. All prior understandings and agreements between the parties are merged into this agreement, and this agreement may not be modified orally or in any manner other than by an agreement in writing signed by both parties. In the event that any provisions of this agreement shall be held to be invalid or unenforceable, the PAGE 4 UNITED CITY OF YORKVILLE SOUTH RECEIVING STATION STANDPIPE (CONSTRUCTION) remaining provisions shall be valid and binding on the parties. The list of Attachments are as follows: Attachment A: Standard Terms and Conditions Attachment B: Scope of Services Attachment C: Estimated Level of Effort and Associated Cost Attachment D: Anticipated Project Schedule Attachment E: 2025 Standard Schedule of Charges Attachment F: EPA 5700-49 Certification of Debarment Suspension Attachment G: [EPA Contract Requirements Attachment H: Supplemental WIFIA Contract Clauses L. Notices: All notices required to be given under the terms of this agreement shall be given mail, addressed to the parties as follows: For the City: City Administrator and City Clerk United City of Yorkville 651 Prairie Pointe Drive Yorkville, IL 60560 For the ENGINEER: Engineering Enterprises, Inc. 52 Wheeler Road Sugar Grove Illinois 60554 Either of the parties may designate in writing from time -to -time substitute addresses or persons in connection with required notices. Agreed to this day of 2025. United City of orkville: Engineering Enterprises, Inc.: � v John Purcell \ Bradley P. Sanderson Mayor Chief Operating Officer /P esident Jori ~ ehland Todd Wells City Clerk Project Manager PAGE 5 SOUTH RECEIVING STATION UNITED CITY OF YORKVILLE STANDPIPE (CONSTRUCTION) STANDARD TERMS AND CONDITIONS Attachment A Agreement: These Standard Terms and Conditions, together with the Professional Services Agreement, constitute the entire integrated agreement between the OWNER and Engineering Enterprises, Inc. (EEI) (hereinafter "Agreement"), and take precedence over any other provisions between the Parties. These terms may be amended, but only if both parties consent in writing. However, to the extent that the Scope of Work differs from the Standard Terms and Conditions, the Scope of Work document controls. Standard of Care: In providing services under this Agreement, the ENGINEER will endeavor to perform in a matter consistent with that degree of care and skill ordinarily exercised by members of the same profession currently practicing under same circumstances in the same locality. ENGINEER makes no other warranties, express or implied, written or oral under this Agreement or otherwise, in connection with ENGINEER'S service. Construction Engineering and Inspection: The ENGINEER shall not supervise, direct, control, or have authority over any contractor work, nor have authority over or be responsible for the means, methods, techniques sequences, or procedures of construction selected or used by any contractor, or the safety precautions and programs incident thereto, for security or safety of the site, nor for any failure of a contractor to comply with laws and regulations applicable to such contractor's furnishing and performing of its work. The ENGINEER neither guarantees the performance of any contractor nor assumes responsibility for contractor's failure to furnish and perform the work in accordance with the contract documents. The ENGINEER is not responsible for the acts or omissions of any contractor, subcontractor, or supplies, or any of their agents or employees or any other person at the site or otherwise furnishing or performing any work. Shop drawing and submittal review by the ENGINEER shall apply to only the items in the submissions and only for the purpose of assessing if upon installation or incorporation in the project work they are generally consistent with the construction documents. OWNER agrees that the contractor is solely responsible for the submissions and for compliance with the construction documents. OWNER further agrees that the ENGINEER'S review and action in relation to these submissions shall not constitute the provision of means, methods, techniques, sequencing or procedures of construction or extend or safety programs or precautions. The ENGINEER'S consideration of a component does not constitute acceptance of the assembled items. The ENGINEER'S site observation during construction shall be at the times agreed upon in the Project Scope. Through standard, reasonable means the ENGINEER will become generally familiar with observable completed work. If the ENGINEER observes completed work that is inconsistent with the construction documents, that information shall be communicated to the contractor and OWNER for them to address. Opinion of Probable Construction Costs: ENGINEER'S opinion of probable construction costs represents ENGINEER'S best and reasonable judgment as a professional engineer. OWNER acknowledges that ENGINEER has no control over construction costs of contractor's methods of determining pricing, or over competitive bidding by contractors, or of market conditions or changes thereto. ENGINEER cannot and does not guarantee that proposals, bids or actual construction costs will not vary from ENGINEER'S opinion of probable construction costs. Copies of Documents & Electronic Compatibitity: Copies of Documents that may be relied upon by OWNER are limited to the printed copies (also known as hard copies) that are signed or sealed by the ENGINEER. Files in electronic media format of text, data, graphics, or of other types that are furnished by ENGINEER to OWNER are only for convenience of OWNER. Any conclusion or information obtained or derived from such electronic files will be at the user's sole risk. When transferring documents in electronic media format, ENGINEER makes no representations as to long term compatibility, usability, or readability of documents resulting from the use of software application packages, operating systems, or computer hardware differing from those used by ENGINEER at the beginning of the project. Changed Conditions: If, during the term of this Agreement, circumstances or conditions that were not originally contemplated by or known to the ENGINEER are revealed, to the extent that they affect the scope of services, compensation, schedule, allocation of risks, or other material terms of this Agreement, the ENGINEER may tail for renegotiation of appropriate portions of this Agreement. The ENGINEER shall notify the OWNER of the changed conditions necessitating renegotiation, and the ENGINEER and the OWNER shall promptly and in good faith enter into renegotiation of this Agreement to address the changed conditions. if terms cannot be agreed to, the parties agree that either party has the absolute right to terminate this Agreement, in accordance with the termination provision hereof. Hazardous Conditions: OWNER represents to ENGINEER that to the best of its knowledge no Hazardous Conditions (environmental or otherwise) exist on the project site. If a Hazardous Condition is encountered or alleged, ENGINEER shall have the obligation to notify OWNER and, to the extent of applicable Laws and Regulations, appropriate governmental officials. It is acknowledged by both parties that ENGINEER's scope of services does not include any services related to a Hazardous Condition. In the event ENGINEER or any other party encounters a Hazardous Condition, ENGINEER may, at its option and without liability for consequential or any other damages, suspend performance of services on the portion of the project affected thereby until OWNER: (i) retains appropriate specialist consultant(s) or contractor(s) to identify and, as appropriate, abate, remediate, or remove the Hazardous Condition; and (ii) warrants that the project site is in full compliance with applicable Laws and Regulations. ENGINEER PAGE 1 SOUTH RECEIVING STATION UNITED CITY OF YORKVILLE STANDPIPE (CONSTRUCTION) agrees to cooperate with the OWNER, as necessary, to remediate a Hazardous Condition, but same may result in additional costs to the OWNER. Consequential Damages: Notwithstanding any other provision of this Agreement, and to the fullest extent permitted by law, neither the OWNER nor the ENGINEER, their respective officers, directors, partners, employees, contractors, or subcontractors shall be liable to the other or shall make any claim for any incidental, indirect, or consequential damages arising out of or connected in any way to the Project or to this Agreement. This mutual waiver of consequential damages shall include, but is not limited to, loss of use, loss of profit, loss of business, loss of income, loss of reputation, or any other consequential damages that either party may have incurred from any cause of action including negligence, strict liability, breach of contract, and breach of strict or implied warranty. Roth the OWNER and the ENGINEER shall require similar waivers of consequential damages protecting all the entities or persons named herein in all contracts and subcontracts with others involved in this project. Termination: This Agreement may be terminated for convenience, without cause, upon fourteen (14) days written notice of either party. In the event of termination, the ENGINEER shall prepare a final invoice and be due compensation asset forth in the Professional Services Agreement for all costs incurred through the date of termination. Either party may terminate this Agreement for cause upon giving the other party not less than seven (7) calendar days' written notice for the following reasons: (a) Substantial failure by the other party to comply with or perform in accordance with the terms of the Agreement and through no fault of the terminating party; (b) Assignment of the Agreement or transfer of the project without the prior written consent of the other party; (c) Suspension of the project or the ENGINEER'S services by the OWNER for a period of greater than ninety (90) calendar days, consecutive or in the aggregate. (d) Material changes in the conditions under which this Agreement was entered into, the scope of services or the nature of the project, and the failure of the parties to reach agreement on the compensation and schedule adjustments necessitated by such changes. Payment of Invoices: Invoices are due and payable within 30 days of receipt unless otherwise agreed to in writing. Third Party Beneficiaries: Nothing contained in this Agreement shall create a contractual relationship with or a cause of action in favor of a third party against either the OWNER or the ENGINEER. The ENGINEER'S services under this Agreement are being performed solely and exclusively for the OWNER'S benefit, and no other party or entity shall have any claim against the ENGINEER because of this Agreement or the performance or nonperformance of services hereunder. The OWNER and ENGINEER agree to require a similar provision in all contracts with contractors, subcontractors, vendors and other entities involved in this Project to carry out the intent of this provision. Force Majeure: Each Party shall be excused from the performance of its obligations under this Agreement to the extent that such performance is prevented by force majeure (defined below) and the nonperforming party promptly provides notice of such prevention to the other party. Such excuse shall be continued so long as the condition constituting force majeure continues. The party affected by such force majeure also shall notify the other party of the anticipated duration of such force majeure, any actions being taken to avoid or minimize its effect after such occurrence, and shall take reasonable efforts to remove the condition constituting such force majeure. For purposes of this Agreement, '"force majeure" shall include conditions beyond the control of the parties, including an act of God, acts of terrorism, voluntary or involuntary compliance with any regulation, law or order of any government, war, acts of war (whether war be declared or not), labor strike or lock -out, civil commotion, epidemic, failure or default of public utilities or common carriers, destruction of production facilities or materials by fire, earthquake, storm or like catastrophe. The payment of invoices due and owing hereunder shall in no event be delayed by the payer because of a force majeure affecting the payer. Additional Terms or Modification: All prior understandings and agreements between the parties are merged into this Agreement, and this Agreement may not be modified orally or in any manner other than by an Agreement in writing signed by both parties. In the event that any provisions of this Agreement shall be held to be invalid or unenforceable, the remaining provisions shall be valid and binding on the parties. Assignment: Neither party to this Agreement shall transfer or assign any rights or duties under or interest in this Agreement without the prior written consent of the other party. Subcontracting normally contemplated by the ENGINEER shall not be considered an assignment for purposes of this Agreement. Waiver: A party's waiver of, or the failure or delay in enforcing any provision of this Agreement shall not constitute a waiver of the provision, nor shall it affect the enforceability of that provision or of the remainder of this Agreement. Attorney's Fees: In the event of any action or proceeding brought by either party against the other under this Agreement, the prevailing party shall be entitled to recover from the other all costs and expenses including without limitation the reasonable fees of its attorneys in such action or proceeding, including costs of appeal, if any, in such amount as the Court may adjudge reasonable. Fiduciary Duty: Nothing in this Agreement is intended to create, nor shall it be construed to create, a fiduciary duty owed to either party to the other party. EEI makes no warranty, express or implied, as to its professional services rendered. Headings: The headings used in this Agreement are inserted only as a matter of convenience only, and in no way define, limit, enlarge, modify, explain or define the text thereof nor affect the construction or interpretation of this Agreement. PAGE 2 UNITED CITY OF YORKVILLE SOUTH RECEIVING STATION STANDPIPE (CONSTRUCTION) SCOPE OF SERVICES Attachment B SOUTH RECEIVING STATION STANDPIPE CONSTRUCTION ENGINEERING United City of Yorkville, IL The United City of Yorkville is constructing a 1.5 MG Standpipe on a 4.01-acre site at 8621 IL Route 126 for the future South Receiving Station, including site grading and connection water main. Our scope of services related to this project includes Construction Engineering. Below is a list of work items in more detail: CONSTRUCTION ENGINEERING 3-1 Construction Administration o Precon Meeting (Preparation and Attendance) o Review of Shop Drawings o Obtain/Provide All Construction Documents from Contractor o Prepare and Coordinate Operating Permit from the IEPA o Prepare Pay Estimates o Daily[Weekly Updates to City o Bi-weekly Progress Meetings (Assuming 52 Active Construction Weeks) o On -going Communication/Coordination with Contractor (RFIs) o Review and Delivery of Warranties o Perform Substantial Completion Inspection o Punchlist o Two -Year Anniversary Review & Warranty 3-2 Construction Layout and Record Drawings 3-3 Construction Observation (Assuming 52 Active Construction Weeks) - Construction observation work will range from park -time to full-time efforts depending on the contractor's work activity and the criticality of the associated work activity. DIRECT EXPENSES/SUB-CONSULTANTS Mileage • Geotechnical Engineering Services • Electrical Engineering Services This Scope of Work and associated Estimated Level of Effort and Associated Cost (Attachment D) assume a project completion date of November 27, 2026, except for warranty on anniversary review work which would be completed by November 27, 2029. If work extends beyond this completion date, the additional work shall be considered outside the scope of the base contract and will be billed in accordance with the Standard Schedule of Charges. PAGE 1 UNITED CITY OF YORKVILLE SOUTH RECEIVING STATION STANDPIPE (CONSTRUCTION) Furthermore, the above scope for "SOUTH RECEIVING STATION STANDPIPE — CONSTRUCTION ENGINEERING" summarizes the work items that will be completed for this contract. Additional work items, including additional meetings beyond the meetings defined in the above scope shall be considered outside the scope of the base contract and will be billed in accordance with the Standard Schedule of Charges. PAGE 2 ATTACHMENT C: ESTIMATE OF LEVEL OF EFFORT AND ASSOCIATED COSTCLENT PROFESSIONAL ENGINEERING SERVICES PROJECT United Ci of Yorkville i YO 2417 PROJECT South Receiving Station Stand i e - Construction Engineering 4I25125 7AW TASK NO, TASK DESCRIPTION COST PERSON BPS MGS TAW MWS AMN JMB KKP DRA HOURS Precon Meeting (Preparation and Attendance 3 6 3 3 15 $ 3,225 Review of Shop Drawings 8 28 36 $ 6,WA ObtainfProvide Construction Documents 4 4 8 $ 1,532 Prepare and Coordinate OperatingOperatirg Permit from EPA 4 4 8 $ 1,532 Daili Updates to Ci 13 52 52 117 $ 22.750 Bi-WeeklyProgress Meetings 22 11 22 22 77 $ 16,456 CommunicationlCcordlnation with Contractor RFIs 8 16 40 1 8 72 $ 12,672 Review and Delivery of Warranty 1 1 1 3 $ fiat Perform Substantial Complete Insiaection 1 2 8 8 18 $ 3,500 Punchlist 8 16 24 $ 4.464 Three -Year Anniversary Review and Warranty 8 16 24 $ 4,464 Task Subtotal: 251 41 134 194 8 4D2 $ 77,760 Office Preparation 4 4 $ 972 Field Staking 35 35 $ 6,370 As -Bulls 10 10 $ 1.920 Easement Review and Staking 3 3 $ 546 Task Subtotal: 4 48 52 $ 9.708 Construction ObservatlOn 22 284 1,320 1.626 $ 294,868 $ - Task Subtotal: 221 2841 1,320 1,626 $ 294,868 EEISTAFF BPS Bradley P. Sanderson, PE TAW Todd A. Wells, PE MWS Michael W. Schweisthal, PE AMN Adam M. Noon, Et MGS Mark G, Scheller, PLS JMB Joshua M. Boatman, PLS KKP Kdstopher K. Pung DRA Deborah R- Anderson TOTAL COSTS $ 394,744 a ° z � 3 m z m '{ G • m VJ 1 rru v m v C r m L n z r m m �n n C Z m L n z m m m a a C Z m c r C r ' O � C C m • � L7 G7 m � � n z m O � O 0 m n O � O 0 m � m n 0 < ENGINEERING ENTERPRISES, INC. 52 Wheeler Road, Sugar Grove, IL 60554 Ph: 630.466.6700 • Fx: 630.466.6701 www.eeiweb.com EMPLOYEE DESIGNATION CLASSIFICATION Senior Principal E-4 Principal E-3 Senior Project Manager Project Manager Senior Project Engineer/Surveyor 11 Senior Project Engineer/Surveyor I Project Engineer/Surveyor Senior Engineer/Surveyor Engineer/Surveyor Associate Engineer/Surveyor Senior Project Technician 11 Senior Project Technician I Project Technician Senior Technician Technician Associate Technician Engineering/Land Surveying Intern Director of Marketing and Business Development Marketing Coordinator Executive Administrative Assistant Administrative Assistant E-2 E-1 P-6 P-5 P-4 P-3 P-2 P-1 T-6 T-5 T-4 T-3 T-2 T-1 I-1 M-4 M-2 A-4 A-3 HOURLY RATE $256.00 $251.00 $243.00 $218.00 $208.00 $193.00 $175.00 $161.00 $146.00 $132.00 $182.00 $171.00 $159.00 $146.00 $132.00 $115.00 $ 85.00 $135.00 $100.00 $ 80.00 $ 75.00 VEHICLES. DRONE, EXPERT TESTIMONY, REPROGRAPHICS AND DIRECT COSTS* Vehicle for Construction Observation $ 20.00 Unmanned Aircraft System 1 Unmanned Aerial Vehicle 1 Drone $235.00 Expert Testimony $290.00 In -House Scanning and Reproduction $0.251Sq. Ft. (Black & White) $1.001Sq. Ft. (Color) Reimbursable Expenses (Direct Costs) Cost Services by Others (Direct Costs) Cost + 10% * unless specified otherwise in agreement OUTSTANDING SERVICE • EVERY CLIENT • EVERY DAY :EPA EPA Project Control Number United States Environmental Protection Agency Washington, D.C. 20460 Certification Regarding Debarment, Suspension, and Other Responsibility Matters The prospective participant certifies to the best of its knowledge and belief that it and its principals: (a) Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from covered transactions by any Federal department or agency; (b) Have not within a three year period preceding this proposal been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public: (Federal, State, or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; (c) Are not presently indicted for or otherwise criminally or civilly charged by a government entity (Federal, State, or local) with commission of any of the offenses enumerated in paragraph (1)(b) of this certification; and (d) Have not within a three-year period preceding this application/proposal had one or more public transactions (Federal, State, or local) terminated for cause or default. I understand that a false statement on this certification may be grounds for rejection of this proposal or termination of the award. In addition, under 18 USC Sec. 1001, a false statement may result in a fine of up to $10,000 or imprisonment for up to 5 years, or both. Todd A. Wells - Project Manager Typed Name and Title of Authorized Representative Signature of Authorized Representative 4/25/2025 Date ❑ I am unable to certify to the above statements. May explanation is attached. EPA FORM 5700-49 (11-88) ATTACHMENT G IEPA PROFESSIONAL SERVICES CONTRACT CLAUSES Audit and Access to Records Clause: A. Books, records, documents and other evidence directly pertinent to performance of PWSLPIWPCLP loan work under this agreement shall be maintained in accordance with generally accepted Accounting Principles. The Agency or any of its authorized representatives shall have access to the books, records, documents and other evidence for the purpose of inspection, audit and copying. Facilities shall be provided for access and inspection. B. Audits conducted pursuant to this provision shall be in accordance with auditing standards generally accepted in the United States of America. C. All information and reports resulting from access to records pursuant to the above shall be disclosed to the Agency. The auditing agency shall afford the engineer an opportunity for an audit exit conference and an opportunity to comment on the pertinent portions of the draft audit report. D. The final audit report shall include the written comments, if any, of the audited parties. E. Records shall be maintained and made available during performance of project services under this agreement and for three years after the final loan closing. In addition, those records that relate to any dispute pursuant to the Loan Rules Section 365.650 or Section 662.650 (Disputes) or litigation or the settlement of claims arising out of project performance or costs or items to which an audit exception has been taken, shall be maintained and made available for three years after the resolution of the appeal, litigation, claim or exception. Covenant Against Contingent Fees: The professional services contractor warrants that no person or selling agency has been employed or retained to solicit or secure this contract upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee, excepting bonafide employees. For breach or violation of this warranty, the loan recipient shall have the right to annul this agreement without liability or in its discretion to deduct from the contract price or consideration or otherwise recover, the full amount of such commission, percentage, brokerage, or contingent fee. Certification Regarding Debarment, Suspension and Other Responsibility Matters: Form EPA 5700-49 is signed and attached as part of Attachment F-2. USEPA Nondiscrimination Clause: The contractor (engineer) shall not discriminate on the basis of race, color, national origin or sex in the performance of this contract. The contractor shall carry out applicable requirements of 40 CFR Part 33 in the award and administration of contracts awarded under EPA financial assistance agreements. Failure by the contractor to carry out these requirements is a material breach of this contract which may result in the termination of this contract or other legally available remedies. USEPA Fair Share Percentage Clause, The engineer agrees to take affirmative steps to assure that disadvantaged business enterprises are utilized when possible as sources of supplies, equipment, construction and services in accordance with the [WPC or PWS] Loan Program rules. As required by the award conditions of USEPA's Assistance Agreement with Illinois EPA, the engineer acknowledges that the fair share percentages are 5% for MBEs & 12% for WBEs". ATTACHMENT H SUPPLEMENTAL USEPA 1 WIFIA PROFESSIONAL_ SERVICES CONTRACT CLAUSES ECONOMIC AND MISCELLANEOUS AUTHORITIES DEBARMENT AND SUSPENSION AND PROHIBITIONS RELATING TO VIOLATIONS OF CWA AND CAA WITH RESPECT TO FEDERAL CONTRACTS, GRANTS, OR LOANS Debarment and Suspension. Contractor certifies that it will not knowingly enter into a contract with anyone who is ineligible under the 2 CFR part ISO and part 1532 (per Executive Order 12549, 51 FIR 6370, February 21, 1986) or who is prohibited under Section 306 of the Clean Air Act or Section 508 of the Clean Water Act to participate in the [Project]. Suspension and debarment information can be accessed at http://www.sam.gov. Contractor represents and warrants that it has or will include a term or conditions requiring compliance with this provision in all of its subcontracts under this Agreement. NEW RESTRICTIONS ON LOBBYING Federal Lobbying Restrictions (31 U.S.0 1352). Recipients of federal financial assistance may not pay any person for influencing or attempting to influence any officer or employee of a federal agency, a member of Congress, an officer or employee of Congress, or an employee of a member of Congress with respect to the award, continuation, renewal, amendment, or modification of a federal grant, loan, or contract. These requirements are implemented for USEPA in 40 CFR Part 34, which also describes types of activities, such as legislative liaison activities and professional and technical services, which are not subject to this prohibition. Upon award of this contract, Contractor shall complete and submit to the City the certification and disclosure forms in Appendix A and Appendix B to 40 CFR Part 34. Contractor shall also require all subcontractors and suppliers of any tier awarded a subcontract over $100,000 to similarly complete and submit the certification and disclosure forms pursuant to the process set forth in 40 CFR 34.110.